英文合同

第1篇：英文合同

一.hereby

英文释义:by means of , by reason of this

中文译词:特此,因此,兹

用法:常用于法律文件、合同、协议书等正式文件的开头语；在条款中需要强调时也可用。

语法：一般置于主语后,紧邻主语.

例1：

The Employer hereby covenants to pay the Contractor in consideration of the execution and completion of the Works and the remedying of defects therein the Contract Price or such other sum as may become payable under the provisions of the Contract at the time and in the manner prescribed by the Contract.

参考译文:

业主特此立约保证在合同规定的期限内,按合同规定的方式向承包人支付合同价,或合同规定的其它应支付的款项,以作为本工程施工、竣工及修补工程中缺陷的报酬。

注释:

(1)hereby: by reason of this 特此

(2)covenant: v. make a formal agreement 立约,签订合同、条约; n. legal agreement具有法律约束的正式合同

(3)completion of the Works: 工程的竣工

(4)therein: in the Works在本工程中

(5)the Contract Price: 合同总价,指工程的总造价

(6)such...as: 关系代词,相当于that, which

(7)under: in accordance with 根据,按照

(8)the provisions of the Contract: terms and conditions of the Contract合同条款

例2：

We hereby certify to the best of our knowledge that the foregoing statement is true and correct and all available information and data have been supplied herein, and that we agree to provide documentary proof upon your request.

注释：

（1）hereby：特此

（2）to the best of our knowledge：as far as we know据我们所知

（3）foregoing statement：above-mentioned statement上述声明

（4）herein：in this, in the statement在声明中

（5）documentary proof：证明文件

参考译文：

特此证明，据我们所知，上述声明内容真实，正确无误，并提供了全部现有的资料和数据，我们同意，应贵方要求出具证明文件。

例3：

This Contract is hereby made and concluded by and between Co. (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B) on (Date), in (Place), China, on the principle of equality and mutual benefit and through amicable consultation.

注释：

（1）hereby：特此

（2）hereinafter referred to as Party A：以下称甲方

（3）on the principle of equality and mutual benefit：在平等互利基础上

（4）through amicable consultation：通过友好协商

参考译文：

本合同双方， 公司（以下称甲方）与 公司（以下称乙方），在平等互利基础上，通过友好协商，于 年 月 日在中国 （地点），特签订本合同。

例4：

This agreement is hereby made and entered into on (Date), by and between Co. China (hereinafter referred to as Party A) and Co. (hereinafter referred to as Party B).

注释：

（1）this agreement is hereby made and entered into：特此订立本协议 在法律文件中表示“订立本协议”可用以下4个动词：sign (make, conclude or enter into) this agreement, 按照同义词连用的写作特点，可用上述4个动词中的两个来表示）。

（2）hereinafter referred to as Party B：以下简称乙方

参考译文：

本协议特由中国 公司（以下简称甲方）与 公司（以下简称乙方）于 年 月 日订立。

二 hereof

英文释义: of this

中文译词:关于此点；在本文件中

用法:在表示上文已提及的“本合同的、本文件的??”时，使用该词。例如表示本合同条件、条款时，可以说“the terms, conditions and provisions hereof”，这里hereof表示“of this Contract”；又如表示本工程的任何部分，可用“any parts hereof”，这里hereof表示“of this Works”。 语法：一般置于要修饰的名词的后面，与之紧邻。

hereof和thereof的区别：hereof强调“of this”。例如，上面的“the terms, conditions and provisions thereof”中的thereof表示of the Contract；“any parts thereof”中的thereof表示of the Works。

例1

Whether the custom of the Port is contrary to this Clause or not, the owner of the goods shall, without interruption, by day and night, including Sundays and holidays (if required by the carrier), supply and take

delivery of the goods. Provided that the owner of the goods shall be liable for all losses or damages including demurrage incurred in default on the provisions hereof.

注释：

（1） Whether the custom of the Port is contrary to this Clause or not：不论港口习惯是否与本款规定相反，whether? or not：不论??是否

（2） the owner of the goods：货方

（3） without interruption：无间断地

（4） carrier：承运人

（5） in default on the provisions hereof：违反本款规定 hereof：of this Clause

参考译文：

不论港口习惯是否与本款规定相反，货方都应昼夜地，包括星期日和假日（如承运人需要），无间断地提供和提取货物。货方对违反本款规定所引起的所有损失或损坏，包括滞期应负担赔偿责任。

例2

Foreign trade dealers as mentioned in this Law shall, in accordance with the provisions hereof, cover such legal entities and other organization as are engaged in foreign trade dealings.

注释：

（1） foreign trade dealers：对外贸易经营者

（2） as mentioned in this Law：本法所称

（3） the provisions hereof：the provisions of this Law 本法规定

（4） legal entity：法人

（5） be engaged in foreign trade dealings：从事对外贸易经营活动 参考译文：

本法所称对外贸易经营者，是指依照本法规定从事对外贸易经营活动的法人和其他组织。

例3

The establishment of a limited liability company or a company limited by shares shall comply with the conditions and provisions of this Law. A company complying with the conditions and provisions hereof may be registered as a limited liability company or a company limited by shares. Provided that if a company fails to comply with the conditions and provisions hereof, the company in question shall not be registered as a limited liability company or a company limited by shares.

注释：

（1）a limited liability company：有限责任公司

（2）a company limited by shares：股份有限公司

（3）provisions hereof：本法规定 hereof: of this Law

（4）may be registered as：登记为

参考译文：

设立有限责任公司、股份有限公司，必须符合本法规定的'条件。符合本法规定的条件的，登记为有限责任公司或者股份有限公司；不符合本法规定的条件的，不

得登记为有限责任公司或股份有限公司。

例4

If, as a result of withdrawal or any other reasons, an arbitrator fails to perform his duties as an arbitrator, another arbitrator shall, in accordance with the provisions hereof, be selected or appointed. 注释：

（1） as a result of withdrawal or any other reasons：回避或者其它原因

（2） arbitrator：仲裁员

（3） the provisions hereof：the provisions of this Law 本法规定

（4） be selected or appointed：选定或指定

参考译文：

仲裁员因回避或者其它原因不能履行职责的，应当依照本法规定重新选定或指定仲裁员。

例5

In the event of conflict between the provisions on arbitration formulated and prepared prior to the effective date of this Law and the provisions of this Law, the provisions hereof shall prevail.

注释：

（1） conflict：相抵触

（2） prior to the effective date of this Law：本法施行前

（3） the provisions hereof shall prevail：以本法为准 hereof：of this Law 参考译文：

本法施行前制定的有关仲裁的规定与本法的规定相抵触的，以本法为准。 例6

Where, in accordance with laws, the circumstance(s) specified in Article 15 and Article 16 of this Law is /are confirmed, the organization with compensatory obligations shall pay compensation in any of the circumstance in question.

Where the claimant for compensation demands the confirmation of one of the circumstances specified in Article 15 and Article 16 hereof, and the demanded organization refuses to make the confirmation, the claimant shall have the right to lodge a complaint. Where the claimant claims compensation, the claim, shall, first, be lodged to the organization for compensatory obligations.

The provisions of Article 10, Article 11 and Article 12 hereof shall apply to/ in the procedures of compensation.

注释：

（1） the organization with compensatory obligations：赔偿义务机关

（2） shall pay compensation：应当给予赔偿

（3） the claimant for compensation：赔偿请求人

（4） Article 15 and Article 16 hereof：本法第十五条、第十六条 hereof：of this Law

（5） shall have the right to lodge a complaint：有权申诉

（6） claims compensation：要求赔偿

（7） apply to/ in：适用 More Examples: The comment applies equally here. /That argument does not apply in this case. /That applies to at least nine-tenths of the people we see about. /These remarks apply to every town in this kingdom. /The rules of safe driving apply to everyone. 参考译文：

赔偿义务机关对依法确认有本法第十五条、第十六条规定的情形之一的，应当给予赔偿。

赔偿请求人要求确认有本法第十五条、第十六条规定情形之一的，被要求的机关不予确认的，赔偿请求人有权申诉。赔偿请求人要求赔偿，应当先向赔偿义务机关提出。赔偿程序适用本法第十条、第十一条、第十二条的规定。

例7

If an arbitrator involved in one of circumstances specified in Item 4, Article 34 of this Law, and if it is serious, or those specified in Item 6, Article 58 hereof, the arbitrator in question shall, in accordance with the law, bear the legal liability and responsibility. The arbitration commission shall remove the name of the arbitrator in question from the list of arbitrators.

注释：

（1） arbitrator：仲裁员

（2） Article 58 hereof：本法第五十八条 hereof：of this Law

（3） bear the legal liability and responsibility：承担法律责任

（4） the arbitration commission：仲裁委员会

（5） remove the name of the arbitrator in question from the list of arbitrators：将其除名

参考译文：

仲裁员有本法第三十四条第四项规定的情形，情节严重的，或者有本法第五十八条第六项规定的情形的，应当依法承担法律责任，仲裁委员会应当将其除名。 例8

If, pursuant to this Law, the relevant responsible authorities with the duty of approvals fail to grant approval to such an application as meets the requirements and provisions hereof, or the company registration authorities fail to register a company whose application meets the requirements hereof, the party in question may, in accordance with laws, apply for reconsideration or bring an administrative suit.

注释：

（1） the relevant responsible authorities with the duty of approvals：履行审批职责的有关主管部门

（2） meets the requirements and provisions hereof：符合本法条件

（3） the company registration authorities：负责公司登记的主管部门

（4） the requirements hereof：本法条件 hereof: of this Law

（5） apply for reconsideration：申请复议

（6） bring an administrative suit：提起行政诉讼

第2篇：英文合同

合 同 CONTRACT

日期： 合同号码：

Date： Contract No.：

买 方： （The Buyers） 卖方： （The Sellers）

兹经买卖双方同意按照以下条款由买方购进，卖方售出以下商品：

This contract is made by and between the Buyers and the Sellers； whereby the Buyers agree to buy and the Sellers agree to sell the under-mentioned goods subject to the terms and conditions as stipulated hereinafter：

（1） 商品名称：

Name of Commodity：

（2） 数 量：

Quantity：

（3） 单 价：

Unit price：

（4） 总 值：

Total Value：

（5） 包 装：

Packing：

（6） 生产国别：

Country of Origin ：

（7） 支付条款：

Terms of Payment：

（8） 保 险：

insurance：

（9） 装运期限：

Time of Shipment：

（10） 起 运 港：

Port of Lading：

（11） 目 的 港：

Port of Destination：

（12）索赔：在货到目的口岸45天内如发现货物品质，规格和数量与合同不附，除属保险公司或船方

责任外，买方有权凭中国商检出具的检验证书或有关文件向卖方索赔换货或赔款。

Claims：

Within 45 days after the arrival of the goods at the destination， should the quality， Specifications or quantity be found not in conformity with the stipulations of the contract except those claims for which the insurance company or the owners of the vessel are liable， the Buyers shall， have the right on the strength of the inspection certificate issued by the C.C.I.C and the relative documents to claim for compensation to the Sellers

（13）不可抗力：由于人力不可抗力的原由发生在制造，装载或运输的.过程中导致卖方延期交货或不

能交货者，卖方可免除责任，在不可抗力发生后，卖方须立即电告买方及在14天内以

空邮方式向买方提供事故发生的证明文件，在上述情况下，卖方仍须负责采取措施尽

快发货。

Force Majeure ：

The sellers shall not be held responsible for the delay in shipment or non-deli-very of the goods due to Force Majeure， which might occur during the process of manufacturing or in the course of loading or transit. The sellers shall advise the Buyers immediately of the occurrence mentioned above the within fourteen days there after . the Sellers shall send by airmail to the Buyers for their acceptancea certificate of the accident. Under such circumstances the Sellers， however， are still under the obligation to take all necessary measures to hasten the deliveryof the goods.

（14）仲裁：凡有关执行合同所发生的一切争议应通过友好协商解决，如协商不能解决，则将分歧提

交中国国际贸易促进委员会按有关仲裁程序进行仲裁，仲裁将是终局的，双方均受其约

束，仲裁费用由败诉方承担。

Arbitration ：

All disputes in connection with the execution of this Contract shall be settled friendly through negotiation. in case no settlement can be reached， the case then may be submitted for arbitration to the Arbitration Commission of the China Council for the Promotion of International Trade in accordance with the Provisional Rules of Procedure promulgated by the said Arbitration Commission . the Arbitration committee shall be final and binding upon both parties. and the Arbitration fee shall be borne by the losing parties.

买方： 卖方：

（授权签字） （授权签字）

第3篇：英文合同

IRREVOCABLE COMMISSION AGREEMENT 佣

的下列条件发展业务关系：

This Commission Agreement ("Agreement") is between the parties concerned on August , 20xx in Beijing, China on the basis of equality and mutual benefit to develop business on terms and conditions mutually agreed upon as follow: In consideration of the mutual agreements and covenants herein contained, the parties hereto agree as follows: 合约号码:

Contract No. :

1. 协议开始日期: AGREEMENT INITIATION DATE:

本协议从 ___________ , 20xx开始生效。 This agreement enters into force on _______________ , 20xx.

2. 协议方: PARTIES:

本协议涉及以下各方:

This agreement is made and entered by and between:

甲方: PARTY A:

公司: COMPANY:

地址: ADDRESS:

国家: COUNTRY:

电话: TEL:

传真: FAX:

电子邮件: E-MAIL:

AND 和

乙方: PARTY B:

公司: COMPANY:

地址: ADDRESS:

国家: COUNTRY:

电话: TEL:

传真: FAX:

电子邮件: E-MAIL:

金 协 议 本佣金协议书于20xx年08月 日在中国北京由双方在平等互利基础上达成，按双方同意

3. 委任： Appointment

甲方指定乙方为其在中国的全权采购代理，采购甲方指定的烯烃芳烃加氢和异构化催化剂，瓦斯油（AGO+VGO）脱硫催化剂，石脑油加氢催化剂（详见产品采购合同）。

The Party A appoints the Party B as its Exclusive Purchasing Agency in China, purchasing the goods as Part A refers. Olefins, Aromatics Hydrogenation and Isomerisation Catalysts，Gas Oil Desulfurization Catalyst（AGO+VGO），Light Naphtha Hydrotreater Catalyst.(Details as per Purchase Contract)

4. 双方的职责： Duties of two parties:

(1) 甲方所需的采购业务应提交给乙方详细的采购产品信息，比如材质、尺寸、数量、品质等具体要求。Party A shall provide all the information of the purchasing products to Party B, such as material, size, quantity, quality and other concrete requirements.

乙方向甲方提供采购产品客户信息，代理信息，代理租船顾问业务等。负责落实甲方采购产品资源，渠道和谈成供货意向一并介绍给甲方。

Party B shall provide Party A customers’information and agent information, consultancy service on agents chartering. Besides, he shall find and confirm the products resources and supply channel, then introduce these information totally to Party A.

(2) 因甲方购买的产品涉及专利产权和产品生产者指定代理的情况，乙方负责促成甲方与产品生产者或产品生产者代理商之间签署采购协议，实现贸易，并负责为甲方对采购产品取样、验货、出货等的环节进行服务。

Party B shall help and facilitate Party A sign the Purchasing Agreement with the suppliers or agents, also should provide services in many aspects, such as sampling, inspection, delivery and other matters.

5. 货款的支付方式：Payment of goods

甲方购买的产品涉及专利产权或产品生产者指定代理的情况，甲方与产品生产者或产品生产者代理商之间直接签署采购协议，货款支付方式由协议双方协商达成一致。

Party A will sign Purchasing Agreement directly with producers or its agents, and the

payment term of goods will be negotiated and agreed by Party A and the Seller.

6. 佣金的计算、给付方式、给付时间： Commission calculation, payment methods, payment time 甲方同意按照采购产品总金额的（1-5）%支付佣金给乙方，支付日期为付款给卖方的同一天，佣金汇入乙方指定银行账户。如甲方以预付款或分期付款的形式向卖方支付货款，在甲方向卖方支付第一笔货款的同时向乙方全额支付采购产品总金额的佣金。

For the Purchasing Agent's services, the Party A shall pay the Party B the following commission percentage:(1-5)% of Part B’s purchasing aggregate amount of the invoice value,simultaneously within the same banking day as the party A makes payment to the Seller. Commission should be remitted to Party B’s designated bank account. If the Party A makes advance payments to the Seller or payment by installments, he should pay the commission to Party B simultaneously with the first payment he made to the Seller.

7. 违约责任：

(1) 甲方若不按本合同第6条的执行，逾期一天应支付乙方滞纳金，滞纳金系数为：总佣金的5‰/天。

Party A if not in this agreement and article 6, execution of expired day shall pay party B overdue fine, fine for delaying payment coefficient for: the total commission 5‰/ day.

8. 协议的.修改： Modification

此协议书只有经双方共同签字后才能作修改，

This Agreement may not be modified except by amendment reduced to writing and signed by both Parties.

9. 不可抗力： Force Majeure

由于水灾、火灾、地震、干旱、战争或协议一方无法预见、控制、避免和克服的其他事件导致不能或暂时不能全部或部分履行本协议，该方不负责任。但是，受不可抗力事件影响的一方须尽快将发生的事件通知另一方，并在不可抗力事件发生15天内将有关机构出具的不可抗力事件的证明寄交对方。

Either party shall not be held responsible for failure or delay to perform all or any part of this agreement due to flood, fire, earthquake, draught, war or any other events which could not

be predicted, controlled, avoided or overcome by the relative party. However, the party

affected by the event of Force Majeure shall inform the other party of its occurrence in writing as soon as possible and thereafter send a certificate of the event issued by the relevant authorities to the other party within 15 days after its occurrence.

10. 仲裁： Arbitration

因履行本协议所发生的一切争议应通过友好协商解决。如协商不能解决争议，则应将争议提交中国国际经济贸易仲裁委员会(北京)，依据其仲裁规则进行仲裁。仲裁裁决是终局的，对双方都有约束力，仲裁费用，除另有规定外，由败诉一方负担。

All disputes arising from the performance of this agreement shall be settled through friendly negotiation. Should no settlement be reached through negotiation, the case shall then be submitted for arbitration to the China International Economic and Trade Arbitration

Commission (Beijing) and the rules of this Commission shall be applied. The award of the arbitration shall be final and binding upon both parties. Arbitration fees shall be borne by the losing party, unless otherwise awarded.

11. 协议有效期： Validity of Agreement

本协议经有关双方如期签署后生效，有效期为年，从20xx年08月 日到 年 月 日。

This agreement, when duly signed by the both parties concerned, shall remain in force for years, from August , 20xx to XX , XX .

12. 协议的终止： Termination

在本协议有效期内，如果一方被发现违背协议条款，另一方有权终止协议。

During the validity of this agreement, if either of the two parties is found to have violated the stipulations herein, the other party has the right to terminate this agreement.

13. 本协议于20xx年08月 日在北京签订，一式两份，双方各执一份。

This Agreement is signed on ... in Beijing and is in two originals；each Party holds one.

14. 甲方与产品生产者或产品生产者代理商签署的采购协议要向乙方提供一份原件，并在采购协议中将乙方作为甲方代理的身份体现。

The Party A shall provide Party B an original Purchasing Contract signed between him and the Seller, and in the Purchasing Contract, shall show Party B is the Agency of Party A.

甲方: Party A:乙方： Party B:

(签字) (签字)

(Signature)

(Signature)

第4篇：英文合同

租 赁 合 同- LEASE CONTRACT

出租人LESSOR： ______________

(以下简称甲方Hereafter referred to as “PARTY A”)

电话Tel：______________ 手机Mobile：______________

承租人LESSEE：

(以下简称乙方Hereafter referred to as “PARTY B”)

通讯地址Mail Add：

电话Tel： 传真Fax：

住客姓名The occupants of the premises will be：

甲、乙双方经协商一致，订立本合同。合同内容如下：

This lease has been mutual agreed and set up by PARTY A and PARTY B as the following:

1. 出租物业The Premises to be leased are described as follows:

地址Location:

面积Area:

电话Tel: _____条IDD直线, ____ IDD lines

2 租金Rental:

2.1租金每月为 元整， 形式支付

PARTY B shall pay as rent the sum of ; i.e.RMB per month.

2.2租金包括家具和电器的配置(详见附件), 供暖费, 物业管理费、水费,电费,+煤气费、健身卡、卫星收视费。 The Rent includes the Furniture、the Electrical Appliances （see Appendix A）, Heating Fee, Management fee，water fee , electricity fee, gas fee，Fitness card，Satellite TV service fee.

2.3租金应在入住前及此后每月的 号前支付。甲方应在收到租金后向乙方开具正式发票。甲方应每月提前向乙方发出支付租金的书面通知。

The first rental shall be paid before moving in and the following rental shall be paid before the th of each succeeding 1 month’ term. PARTY A shall issue to PARTY B official invoice （Fapiao） upon receiving the rental. Party A shall send prior written notice to Party B for monthly rental payment request.

2.4租金以人民币支票或转账形式支付.

Rental is payable in Ren Min Bi by check or by bank transfer.

2.5 在本租约有效期内，租金不予调整。

Rent will not be modified during the term of this Lease Agreement.

3 押金 Deposit:

3.1乙方须支付相当于两个月房租的押金（即RMB ）, 以人民币支票或转帐形式支付）。甲方应在收到押金后向乙方开具统一收据。

A deposit of two (2) months’ equivalent rental (RMB ) shall be paid by PARTY B in RMB by check or by bank transfer. PARTY A shall issue to PARTY B official receipt upon receiving the deposit.

3.2押金在合同终止后10天内由甲方以相同币种全额退还给乙方（不计利息）。如果延期返还，则每延期一日，按每日万分之四支付给乙方利息。

The deposit shall be refundable in full amount in 10 days after the contract expiration, in same currency and excluding interest thereupon. In case PARTY A delays the refund of the deposit, PARTY A shall pay interest to PARTY B at the rate of 0.04% per day of delay.

3.3甲方应按时付清各种帐单。若以上出租房屋及其家具、设备等因乙方原因出现遗失或非正常的损坏，乙方应负责赔偿。

PARTY A shall pay off on time all the bills due. In case there is any loss or unusual damage to the furnishings, contents or the rental premises due to PARTY B’ s reason, PARTY B shall compensate for it.

4 租期 Lease term:

乙方租用出租房屋期限为 1 年，即自 年 月 日至 年 月 日。

From 16 July 20xx to 15 July 20xx for one (1) year.

5 出租人的责任 PARTY A’s obligation:

5.1 3甲方声明及保证甲方为该出租房屋的合法拥有人，有合法地位出租此房屋，并就出租事宜已取得有关方面的批准。

PARTY A assures to be the legal owner of the leased premises, to have the necessary legal capacity to lease it, and PARTY A’ action has been ratified by the authorities concerned.

5.2租赁期内，若甲方出售该出租房屋导致该出租房屋所有权发生转移,甲方须保证本合同能继续执行。

In case PARTY A sells the premises during the lease which leads to the premises ownership be transferred, PARTY A shall ensure that the said contract will be implemented continuously.

5.3甲方须按时将清洁状况良好的出租房屋交付乙方使用，保证在租赁期内出租房屋内的各项设施能正常使用。 PARTY A shall hand over the said premises to PARTY B on time and assure the said premises will be cleaned and in good status during the lease term.

5.4甲方有义务负责出租房屋及设施的正常维护和保养，如房屋或设施非因甲方原因出现故障，甲方应在收到乙方通知后二十四(24)小时内自行或通过其他方式解决故障，否则，乙方有权雇佣第三方进行维修，由甲方承担所有费用并承担相关责任。由于不可抗力（如地震、台风、洪水、非人为的火灾等）、自然损耗或乙方以外的原因造成的损坏，亦由甲方承担有关费用。

PARTY A shall bear the responsibility of the said premises’ normal repairs and maintenance, and pay the cost related. In case the premises or facilities are in bad conditions not due to the reason of PARTY B, PARTY A shall complete the repair work within 24 hours upon receipt of the notice from PARTY B. Otherwise, PARTY B shall have the right to hire any third parties for the repair work at the cost of PARTY A. The cost of repairs to the said premises, if damaged by Force Majeure (such as earthquake, typhoon, flood non-man made fire, etc) reasonable wear and tear or by accidents beyond PARTY B’S control, should also be borne by PARTY A.

5.5租赁期内，在乙方遵守合同及支付租金的前提下，未经乙方允许，甲方不得进入该出租房屋。

During the lease, PARTY A shall not get in the said premises without PARTY B’S permission if PARTY B has been carrying out the contract normally.

5.6甲方应督促管理公司向乙方提供足够的服务，如冷水、热水、煤气,电的供应及各种设备的正常工作。 Party A shall direct Property Management Company to provide sufficient and continuous services to Party B, including provision of cold water, hot water, gas and electricity and ensure proper maintenance of equipment therein.

5.7 房产税及与租赁有关的所有税费由甲方承担。

Premises tax and other leasing related taxes shall be paid by PARTY A.

6 承租方的责任 PARTY B’S obligations:

6.1 乙方申明及保证其在中国拥有合法居留权，并按有关规定办理必要的居住登记手续。

PARTY B assures to have the legal right of residence in China, and shall complete the residential formalities complying with the local regulations.

6.2 住客应按时支付电话费含上网费、水电煤气费。

The occupant shall pay the telephone bills and internet fee, extra water electricity gas fee on time.

6.3 乙方只能将出租房屋用做住宅，不得将之用作公司及代表处的注册地址，亦不可作为公开的'办公室。 The premises are limited for residential use only by PARTY B, and are prohibited from registering as legal address for any company or agency, or using as public office.

6.4 乙方不得在出租房屋内进行违反法律及政府对出租房屋用途有关规定的行为。

PARTY B shall not carry in the premises any unlawful or illegal activities which are not allowed according to the leasing regulations from the government.

6.5 租赁期内，未经甲方书面同意，乙方不得将出租房屋部分或全部转租他人。

PARTY B shall not partly or totally sublet the said premises without the written permission from PARTY A.

6.6 若因乙方使用不当或不合理使用，出租房屋及其内的设施出现损坏或发生故障，乙方应及时联络管理机构或甲方进行维修，并负责有关维修费用.

The damage of the premises or the fittings that are within the control of PARTY B shall be borne by PARTY B, and PARTY B shall contact the management office or PARTY A instantly.

6.7 租赁期内，乙方对出租房屋进行装修或增加水、电、消防等设施，须经甲方同意并经有关部门批准，并由甲方执行监理，所需费用由乙方承担。双方解约时，乙方不能移走自行添加的结构性设施，甲方亦不必对上述添加设施进行补偿。

PARTY B, upon written permission of PARTY A, may make additions or alterations dealing with water,

electricity supply or fire protection, at his own expense, subject to necessary permits or licenses required by the authorities concerned and under the supervision of PARTY A .No structural alterations or additions can be removed from the premises upon the expiration of this contract. No reimbursement for the said additions.

6.8 乙方有权在墙壁上悬挂画、图片或其他装饰性物品。合同履行期限届满或提前解约时，甲方应承担费用拔掉钉子、粉刷墙壁或使墙壁恢复原状，并承诺不以此为由扣留乙方的押金。

PARTY B is entitled to hang pictures, paintings or other decorative articles on the walls. Upon expiration or early termination of the contract, PARTY A shall bear the cost to remove the nails, repaint the wall or restore the wall to the original state, and PARTY A shall not retain PARTY B’S deposit for the reason of doing things above.

6.9租赁合同期满的前一个月内，经合理事先书面通知，乙方应允许甲方或其授权人 引领潜在客人参观在出租房屋。

During the last month of the contract, after reasonable prior written notice to PARTY B, PARTY A or his nominee shall be allowed to show the said premises to the potential clients.

6.10 租赁期满，若甲，乙双方未达成续租协议，乙方应于租期届满时或之前迁离出租房屋并将钥匙及清理干净的房屋归还甲方.

PARTY B shall return the premises in a clean condition to PARTY A (except wear and tear) at the expiration of the contract if there is no renewal thereupon.

7 提前解约Early termination:

7.1六(6)个月后，乙方如要退租，应提前一(1)个月书面通知甲方终止本租约。在此情况下，甲方应在本租约终止后十(10)日内将押金全额退还乙方。

After six (6) months, Party B may, upon one (1) month advance written notice to Party A, terminate this

Tenancy Agreement without any liabilities. Under this circumstance, Party A shall return the deposit in full to Party B within ten (10) days after the termination.

7.2 若因自然界的不可抗力，如火灾、洪水、台风、地震、战争等意外损害导致出租房屋无法居住，合同即自动终止，甲、乙双方互不承担责任。

If the said premises are so damaged by force majeure (fire, flood, typhoon, earthquake, war, and etc) that it’s no longer habitable, the contract shall be terminated automatically. Neither PARTY A nor PARTY B shall bear any responsibility to each other.

8 续租 Renewal:

租赁期满，乙方有优先续租权，但须提前一个月通知甲方，并安排签订续租合同。

PARTY B retains the priority to renew this lease upon expiration , while one-month prior notice to PARTY A is necessary, and PARTY A shall arrange the signature for the renewal contract.

9 争议的解决 Dispute Resolution:

9．1 本合同适用法律为中华人民共和国相关法律。

The contract is governed by the laws of the People’s Republic of China.

9．2在履行本合同过程中产生的任何争议由双方协商解决，协商不成，可向中国国际经济贸易仲裁委员会(北京)申请仲裁。

In case of any dispute arising out of the performance of this Contract, PARTY A and PARTY B shall consult

together to reach unanimity, otherwise both parties can submit the dispute to the China International Economic and Trade Arbitration Commission (Beijing) for arbitration.

10 其他Others:

10.1本合同以中英文两种文字拟成，两种文本同等有效。

The contract is drawn in both Chinese and English versions. Both texts have equal effect.

10.2 本合同一式二份，甲、乙双方各执一份。

Two copies of the contract will be drawn and remained in the possession of PARTY A & PARTY B. 10.3本合同自签定之日起生效。

The contract shall come into force on the date of signature.

10.4本合同的附件是本合同必不可少的组成部分。附件一列明的物品在甲、乙双方核实签字后生效。

The appendix is an indivisible part of this contract. Details listed in appendix 1 shall not come into affect until being checked and signed by both PARTY A and PARTY B.

11 签章 Signatures and official marks:

甲方 乙方

PARTY A: PARTY B:

授权代表： 授权代表人：

Authorized representative: Authorized representative:

盖章： 盖章：

Seal: Seal:

日期 日期

Date : Date :